Does the owner's delay in settling due payments affect the contractor's commitment to the agreed project duration?
Legal Answer
Radiif AI Legal Assistant
⚡ Quick Answer:
Yes, if the contractor proves that the owner's delay in settling payments was a direct cause for the suspension or delay of the work, then this period shall be added to the project's duration and shall not be calculated as part of the delay period subject to liquidated damages.
Legal References & Citations
العقد (حيث ذكر وكيل المدعى عليه: 'وهذا حسب العقد من أسباب تأخر المشروع وإلزامًا تضاف للمدة الفعلية للمشروع')
Share this answer:
About Radiif
Radiif is an AI legal platform specialized in Saudi Arabian law, providing answers verified by legal references and articles.
This answer is for general legal education and is not legal advice. Please consult a licensed attorney for your specific case.
Page Stats
Do you have specific details about your case?
Ask Radiif AI Legal Assistant now and get verified answers with exact citations from Saudi law.
Do you want to consult a certified lawyer for this case?
We can suggest a list of certified lawyers with extensive expertise specifically in this domain.